Minor works building contract mw download
JCT: Minor Works Building Contract 2016 (MW) by JCT
JCT Minor Works Building Contract, 2011 Edition
Notice to JCT 2016 users
Minor Works Building Contracts are suitable for projects procured via the traditional or conventional method. The Joint Contracts Tribunal Setting the standard for construction contracts.
There are provisions for varying the work, together with mechanisms for adjusting the contract sum and the completion date. In general terms, the contract assumes that all work is designed by the contract administrator. However, it is still very important to carefully consider the insurance provisions contained in Section 5 of the contract and ensure that they meet the project requirements. Section 5 provides for three types of insurance: public liability insurance, employer's liability insurance and insurance of the Works and potentially of existing structures. Public liability insurance covers the contractor's liability arising from death or personal injury to third parties and their liability for damage to property.